General Terms and Conditions of VITLAB GmbH
General Terms and Conditions VITLAB GmbH
1.
General
1.1 These General Terms and Conditions (GT&C) are intended for use in commercial transactions
between businesses.
1.2 These GT&C shall apply for all, including future, contracts with the customer. Other terms and
conditions shall not become part of the contract, even if we do not expressly object to them.
Subsidiary agreements made before or at the time of conclusion of contract may only be invoked if
they are immediately confirmed in writing. The waiver of the requirement for written form shall only
be possible in writing. The language of the contract shall be German or English. In the event of a
discrepancy between the German language version of these GT&C and a version in any language,
the German language version shall prevail.
1.3 Our offers are subject to change and non-binding. We reserve the right to make technical
improvements to our products.
1.4 We may store and process data in our IT system necessary for the purpose of processing the
contract.
1.5 A set-off by the customer shall not be permitted unless the counterclaims are undisputed or legally
established, or pecuniary counterclaims arising from the right to refuse payment pursuant to Section
320 Bürgerliches Gesetzbuch (BGB) (German Civil Code).
1.6 Orders with a goods value of below € 250 shall be subject to a minimum order surcharge of € 50.
Delivery shall be undertaken generally in packaging units (PU) according to the currently valid price
list. For deliveries within five (5) working days or for order values up to € 500, we reserve the right
to waive an order confirmation.
1.7 The place of jurisdiction shall be the court responsible for our head office in Aschaffenburg,
Germany. We shall also be entitled to appeal to the court responsible for the head office of our
customer. We shall, furthermore, as plaintiffs have the right to invoke the Arbitration Court at the
Chamber of Commerce and Industry in Frankfurt am Main, Germany. The Arbitration Court shall, in
this case, make the final judgment in accordance with the Rules of Arbitration of the Chamber of
Commerce and Industry in Frankfurt am Main without recourse to the ordinary courts of law. The
instigation of legal dunning proceedings by us shall not signify the exertion of our right of choice; it
shall be admissible in all cases.
1.8 German law shall apply exclusively under the exclusion of the conflict of laws principles of Private
International Law and the UN Convention on Contracts for International the Sale of Goods (CISG).
2.
Delivery
2.1 The place of performance shall be our factory in Grossostheim, Germany. The risk shall transfer to
the customer when the delivery leaves the ramp at our factory. This shall also apply to partial
deliveries or where we have performed additional services, such as shipping; costs for transport,
packaging or insurance; exportation and installation.
2.2 Insofar as we have agreed to orders on call, the customer must take delivery of the total amount
within six (6) months, at the latest at the date confirmed by us.
2.3 In the case of a delay in the customer’s acceptance of a delivery, we may, without prejudicing our
claim for performance, have the goods put into storage at the cost of the customer or, after
providing a warning and setting a deadline for the customer, otherwise dispose of them.
3.
Delivery Period, Delay
3.1 Delivery times shall be ex works. Delivery periods shall begin on receipt of our order confirmation by
the customer; however only after settlement of any technical issues pending from the conclusion of
the contract; and after receipt of any documents to be provided to us by the customer, such as
drawings, permits or approvals; and definitely not before receipt of agreed advance payments. The
delivery period shall be considered to have been met if readiness for dispatch has been notified
before the expiry of this period. Delivery shall be subject to us receiving our own supplies punctually
and in good order.
3.2 Force Majeure and circumstances beyond our control, such as strikes, lock-outs, operational
disruption, shortages of raw materials and equipment, delayed delivery or non-delivery by our
suppliers, shall extend the delivery periods accordingly and shall release us from our delivery
obligations if they, as a result, render delivery impossible. We shall also not be liable for the
circumstances described above if they arise during an already existing delay. The same shall apply for
any additional or amended services requested by the customer.
3.3 We shall be considered to be in default of delivery only if the customer has issued us with a
reminder, has set a reasonable extension period which has elapsed.
3.4 In the case of delay damages, our liability for compensation shall be limited to 10% of the value of
the delayed delivery/service. The limitation shall not apply in cases of wilful intent, gross negligence
and/or injury to life, limb or health. The customer shall be obliged to immediately inform us in
writing of any likely consequences of delay.
4.
Prices, Terms of Payment
4.1 Prices shall be ex works and exclusive of statutory VAT, if applicable. Costs of packaging,
transportation, freight and insurance shall be borne by the customer. Prices shall also be exclusive of
the cost of returning and recycling/disposing of old equipment.
4.2 Invoices shall be payable to our account in EUROs (€) without deductions and free of charges and
expenses. Payment shall be made immediately or by the date stated. The determinant factor shall be
the receipt of payment. Cheques and bills of exchange shall only be accepted on account of
performance and at the cost of the customer.
4.3 In the case of customers, with whom we are working for the first time or with whom we do not
work regularly, after delay in payment or in the case of reasonable doubt as to the creditworthiness
of the customer, we shall reserve the right to make individual deliveries dependent on their pre-
payment or a security deposit to the value of the invoice amount.
4.4 Should the period between conclusion of contract and agreed delivery exceed four (4) months, so
may we, at our discretion, demand a reasonable additional charge equivalent to the increase in our
costs up until delivery. For deliveries on call, our current price shall apply.
4.5 In the case of an agreed return of goods that are free of defects, the customer shall be charged a
checking and processing fee of 20 % of the invoice amount (minimum € 50).
4.6 Should the customer be in arrears with payment, our debt claims against him shall be due
immediately, and we shall not be obliged to make any further deliveries based on current delivery
contracts.
4.7 If payment is delayed, we shall charge - notwithstanding further damage compensation claims -
interest on arrears at the statutory rate.
4.8 We may offset amounts payable to the customer (e.g. from credit notes) against our claims against
the customer.
5.
Retention of Title, Assignment of Future Claims
5.1 The goods delivered shall remain our property until the complete and unlimited payment. Should
we still have further claims against the customer, we shall then retain our property rights until
payment of these has been effected.
5.2 The customer may neither use goods subject to retention of title nor combine them with other
objects to which a third party may have rights. Should, however, goods subject to retention of title
become, through their combination with other objects, part of a new (complete) item, we shall be a
proportional co-owner of this new item directly, even if this latter component is regarded as the
main component. Our proportion of co-ownership shall be determined by the ratio of the invoice
value of the goods to the value of the new item at the time of combination.
5.3 The customer may resell goods subject to retention of title in the course of his normal business as
long as he has not assigned, pledged or otherwise encumbered his claims from the resale.
5.4 The customer shall assign to us in advance as collateral any claims against his customers from the
resale of the goods subject to retention of title (see Clause 5.3) and/or newly formed items (see
Clause 5.2) to the value of our invoice for the goods subject to retention of title. As long as the
customer is not in default of payment for the goods subject to retention of title, he may collect the
assigned claims in the ordinary course of business. He may, however, only use the proportional
proceeds for the payment to us for the goods subject to retention of title.
5.5 At the customer’s request, we shall release collateral at our discretion if and to the extent that the
nominal value of the collateral exceeds 120% of the nominal value of our outstanding debt claims
against the customer.
5.6 The customer shall be required to inform us immediately of any attachments, seizures or any other
third-party dispositions relating to the goods that are reserved or co-owned by us.
5.7 In the event of failure to pay bills of exchange or cheques, or failure or recall of a payment made by
debit order/direct debit mandate, suspension of payments or insolvency of the customer or of the
end buyer, the rights of the customer under Clause 5.3. shall no longer be valid. The customer must
then immediately inform the buyer of our extended retention of title; he may use the assignment of
relevant proportional proceeds only to pay for the delivered goods.
5.8 Where payment is delayed and in the cases covered in Clause 5.7, we shall be entitled to withdraw
from the contract and/or, without withdrawing from the contract, demand the return of any goods
subject to retention of title still in possession of the customer and to collect the assigned receivables
ourselves. In order to ascertain our rights, we shall be entitled to have all of our customer’s
documents/books concerning our reserved rights examined by a person who is subject to the
professional duty of confidentiality.
6.
Warranty, Limitation of Liability
6.1 We warrant that our delivered goods (including any agreed installation) are free of defects at time
of risk transfer. The required quality, durability and use of our delivered goods are based solely on
the agreed written specification, product description and/or operating manuals. Any information
beyond this, in particular in preliminary discussions, advertising and/or referencing industrial
standards shall only become part of the contract if they are expressly referenced in writing.
6.2 Should the customer requires the delivered goods for purposes other than those agreed, he must
take responsibility himself for examining their special suitability for this - also in terms of product
safety - and ensure their compliance with all relevant technical, legal or regulatory provisions before
the intended use. We shall not be liable for any usability that was not expressly confirmed by us in
writing. In the case of material or design requirements of the customer, we shall accept no liability
for the suitability or permissibility of the desired materials or designs, and shall, in this respect, have
no particular testing obligation. Compliance with safety-related and occupational health regulations
depends on the location and operating conditions of which we have no prior knowledge. Action for
ensuring compliance shall therefore be the responsibility of the customer or his buyer.
6.3 We shall not be liable for the consequences of improper handling, use, maintenance and operation
of the delivered goods; the consequences of normal wear and tear, in particular of wearing parts,
such as pistons, seals, valves; the breakage of glass, plastic or ceramic parts; for the consequences of
chemical, electrochemical or electrical influences; or non-observance of the operating instructions.
6.4 If a notice of defect is justified, we shall initially only be required to provide supplementary
performance. Supplementary performance shall be, at out discretion, either rectification of the
defect or delivery of goods free of defects. Further warranty claims shall only apply in the event of
rejection, impossibility or failure of the supplementary performance. The customer shall bear
additional expenses, which arise from the fact that the goods were taken after delivery to a location
other than the agreed place of performance.
6.5 The customer must, immediately upon receipt of the goods, inspect them carefully, also in terms of
product safety, and notify obvious defects immediately in writing; any hidden defects must be
immediately notified upon discovery. The customer must notify the carrier immediately of any
transport damage. Failure to observe the testing and notification obligation shall void any customer
claims for defects.
6.6 Our liability for slight negligence shall be limited to claims for injury to life, limb or health, to claims
under the Produkthaftungsgesetz (German Product Liability Act) or to claims of culpable breach of
fundamental contractual obligations through which the purpose of the contract is endangered.
Otherwise, our liability for slightly negligent breach of fundamental contractual obligations is limited
to the typically occurring damages which we could have foreseen when the contract was
concluded.
6.7 Should the customer use the delivered goods in conjunction with environmentally harmful, toxic,
radioactive or otherwise hazardous materials, he shall be obliged to clean them before returning
them to us. If applicable, we may charge any necessary costs for decontamination/cleaning and
disposal to the customer’s account.
7.
Limitation Period
The warranty period shall be one year and starts from the date of delivery of the goods to the
customer. The same shall apply for claims for damages, irrespective of their legal basis. The
limitation periods of Section 438 Para. 1 Nos. 1 and 2, Section 479 Para. 1 and Section 634a Para. 1
No. 2 of the BGB (German Civil Code) shall remain unaffected. The restriction of the limitation
period shall not apply to claims based on fraudulent concealment of a defect, for claims under the
Produkthaftungsgesetz (German Product Liability Act) or for damages resulting from injury to life,
limb or health and other damages based on intent or gross negligence. The limitation period in
respect of replaced or repaired goods shall not commence anew.
8.
Software Use
8.1 If software is included in the scope of a delivery, the customer shall be granted a non-exclusive right
to use the software and its associated documentation. It is provided for use on the designated
delivery item. The use of the software on more than one system shall be prohibited.
8.2 The customer shall only be entitled to copy, transfer or translate the software or to convert it from
object code to source code to the extent permitted by law (Sections 69a et seq.
Urheberrechtsgesetz – German Copyright Act). The customer undertakes to refrain from removing
manufacturer information, in particular copyright notices, or from changing these without our prior
express consent or the prior express consent of the software supplier.
8.3 All other rights to the software and the documentation including copies thereof shall remain with us
and/or the software supplier. The issue of sub-licences is not permitted.
9.
Installation
9.1 Installation costs may be invoiced on a monthly basis. Fixed installation prices shall only cover the
work that has been agreed upon. In other cases our current price list for installation and service
costs shall apply.
9.2 The customer shall be responsible for providing the following at his own expense: lighting, motive
power; if necessary, compressed air; water; electrical power for welding and heating, including the
necessary connections; electrical installations to connect the products supplied by us; the devices
required (such as lifting equipment); a lockable room that can be used for storing materials; tools
and clothing during the installation.
10. Spare Parts, Maintenance/Repair and Calibration
10.1 For spare parts and maintenance, repair and calibration services, the current repair and exchange
price list shall apply.
10.2 Insofar as there is an obligation on our part to maintain/supply spare parts, then this obligation shall
be limited to a period of five (5) years from the date of delivery. If spare parts are not manufactured
by us, or are no longer available on the market, for example electronic components, or if the raw
material for their production is no longer available, our obligation to deliver spare parts shall lapse.
10.3 For calibration and maintenance, expendable items from VITLAB production are normally used.
10.4 Maintenance and calibration services can only be provided if the customer has declared the devices
sent to be safe to work on from a health hazard perspective.
10.5 For repair/service values of up to € 50, we reserve the right not to provide a separate cost estimate.
11. Legal Reservation, Industrial Property Rights, Confidentiality
11.1 We reserve ownership and all industrial property rights and copyrights to all moulds, tools or other
devices, samples, pictures, and business and technical documents produced or provided by us. This
also applies where the customer has wholly or in part taken on the costs hereof. The customer may
use these only in the manner agreed with us. Without our written consent, he may not himself
manufacture contractual objects delivered or have the same manufactured by third parties.
11.2 Insofar as we deliver goods according to the designs or other requirements specified by the
customer (models, patterns etc.), the customer shall be liable to us by default for ensuring that,
through the manufacture and delivery of these goods, the industrial property rights or other rights
of third parties are not infringed. If the customer is at fault he shall reimburse us all damage
resulting from any such infringement of rights.
11.3 Any information acquired from this business relationship and not deemed to be public knowledge
must not be disclosed by the customer to third parties.
Status as of: January 2014
159